These Terms and Conditions (“Terms”) govern the use of the website and services provided by BixoSoft (Private) Limited (“BixoSoft”, “Company”, “we”, “our”, or “us”). By accessing our website or engaging our services, you agree to be legally bound by these Terms. If you do not agree with these Terms, please do not use our website or services.
Legal Name: BixoSoft
Business Address: [Insert Full Address, Faisalabad, Pakistan]
Email: info@bixosoft.com
Phone: [Insert Phone Number]
BixoSoft provides professional software development services, including but not limited to:
All services are delivered based on mutually agreed proposals, quotations, or contracts.
Each project will be governed by a separate written agreement, proposal, or statement of work (SOW) outlining project scope, deliverables, timeline, pricing, and payment milestones. In case of conflict between these Terms and a signed agreement, the signed agreement shall prevail.
All prices are quoted and invoiced in Pakistani Rupees (PKR) unless otherwise agreed in writing. Payments must be made according to agreed milestones. Delayed payments may result in project suspension. BixoSoft reserves the right to charge late payment fees where applicable. We do not process or hold third-party funds unrelated to our services.
Refunds are governed by the Refund Policy published on our website. Generally:
Clients agree to provide accurate project requirements, deliver content/assets and feedback on time, review and approve deliverables promptly, and ensure their project does not violate applicable laws. Project delays caused by the client may affect delivery timelines.
Unless otherwise agreed in writing:
Both parties agree to keep confidential information private and not disclose it to third parties without prior written consent, except as required by law.
Clients may not use our services for illegal activities, fraudulent schemes, financial scams, gambling platforms (unless legally licensed), pyramid or prohibited MLM schemes, or any activity that violates applicable laws. BixoSoft reserves the right to refuse or terminate services for projects that involve unlawful or unethical conduct.
To the maximum extent permitted by law:
Projects may integrate third-party tools, APIs, or services. BixoSoft is not responsible for changes in third-party pricing, API modifications, service outages, or policy changes from third-party providers.
Visitors agree not to attempt unauthorized access to systems, introduce malicious code, copy website content without permission, or misrepresent their identity.
Personal information is handled according to our Privacy Policy available on our website.
Either party may terminate a project agreement in writing. Upon termination, payment for completed work remains due, and deliverables completed up to termination may be released upon settlement.
We shall not be liable for delays or failure to perform due to circumstances beyond our reasonable control, including natural disasters, internet outages, government actions, war, or civil unrest.
These Terms shall be governed by and interpreted in accordance with the laws of Pakistan. Any disputes shall be subject to the jurisdiction of the courts of Pakistan.
We reserve the right to update these Terms at any time. Updated versions will be published on this page with the revised effective date.
BixoSoft
Office#509, 5th floor, Mezan Executive Tower, Liaqat Road, Faisalabad, Punjab, Pakistan
Email: info@bixosoft.com
Phone: [+92 (314) 7535677]
